5.34.910 Waiver of Delay Damages Against Public Policy.

City Code Section

Any clause in a Public Improvement Contract purporting to waive, release, or extinguish the rights of a Contractor to damages resulting from The City’s unreasonable delay in performing the Contract is void and unenforceable, as against public policy. However, Contract provisions requiring notice of delay, providing for alternative dispute resolution such as arbitration (where allowable) or mediation, providing other procedures for settling Contract disputes, or providing for reasonable liquidated damages, are permissible.